Construction Contracts Act 2002 – Court of Appeal upholds statutory demand.

March 8, 2015

In this month’s article I wish to review the very recent decision (10 November 2014) of Sol Trustees Limited v Giles Civil Limited.  This was an appeal from a High Court decision which declined an application to set aside two statutory demands based on payment claims. 

 

The Facts. 

Sol Trustees Ltd (SOL) and Giles Civil Limited (Giles) were parties to a construction contract.  Sol was the principal and Giles was the contractor.  The contract terms included the terms in New Zealand Standard 3910:2003 Conditions of Contract for Building and Civil Engineering Construction.  Airey Consultants was the Engineer to the contract. 

 

The process for certification of progress payments was as follows:-

  • Giles was to send its payment claims to both SOL and Airey Consultants;
  • Airey Consultants would then issue a provisional progress payment schedule certifying the amount due;
  • SOL had three working days to respond.

 

Construction commenced on 17 December 2012.  The original scheduled completion date was 17 May 2013.  The work was not completed by that date. 

 

The difficulties between the two parties began in October 2013 when Airey Consultants sent a provisional payment certificate to SOL in the sum of $565,366.  By email SOL asserted the claim was disputed.  It also prepared a spreadsheet which itemised the costs SOL had incurred as a result of delays.  The total loss attributed to the delayed completion was $1,121,747. 

 

A meeting took place as between SOL, Giles and Airey Consultants as to this provisional payment certificate.  No resolution was reached although subsequent to it, SOL paid Giles $250,000. 

 

Payment claim 11 was subsequently issued by Giles for the sum of $365,520.32.  Once again SOL advised that the claim was disputed and subject to be offset by the liquidated damages claim under the contract.  At that point Giles requested a formal decision on whether it was entitled to extensions of time and whether SOL could prove damage as a consequence of any delays.  Ultimately Giles was granted its extensions of time, and no liquidated damages were found against it.

 

Payment claim 12 was then submitted.  SOL notified the parties in a short email that it disputed Payment Claim 12. 

 

Payment claims 13 and 14 were submitted, and nothing more than a short form response was received stating that the amounts claimed were disputed.  Two separate statutory demands were issued in respect of the amounts sought in the Payment Claims. 

 

High Court decision upheld.

The issue before the High Court was whether in fact SOL had issued valid payment schedules within the requisite time frame.  The High Court ruled that neither the spreadsheet nor the emails sent in reply were sufficient to be called payment schedules for the purposes of the Act.  There was no basis to set aside the statutory demands. 

 

The Court of Appeal (with three Judges sitting) made use of the findings within the decisions of George Developments Ltd v Canam Construction Limited as well as Marsden Villas Ltd v Wooding Construction Ltd.  Whilst the Court of Appeal agreed that technical quibbles should not be allowed to vitiate a payment claim or a payment schedule, the issue at stake on appeal was whether the documents SOL relied upon, substantially complied with the payment schedule requirements. 

 

The Court of Appeal held that it is clearly insufficient to simply assert that an amount claimed is disputed, which is as far as SOL’s email responses to the payment claims went.  SOL’s attempt to incorporate the earlier spreadsheet as part of its payment schedule also did not assist as it did not qualify as a payment schedule.  At best it was SOL’s calculation of a potential counterclaim or set off for delay.  It also held that the claim set out did not fall within the limited circumstances set out in section 79 of the Construction Contracts Act 2002 where a set off/counterclaim might defeat proceedings brought for an unresponded to payment claim namely:- (a)judgment has been entered for a liquidated sum that equals or exceeds the claimed amount;

(b) or the set off/counterclaim amount is agreed by the parties. 

 

The High Court decision refusing to set aside the statutory demands was upheld. 

 

To be noted.

No doubt critical in the finding against SOL, was the fact that it had made no or little effort to work through the items claimed in the payment claims in any systematic way, setting out reasons why the sums sought in the payment claims were not owed. 

 

NOTE: This article is not intended to be legal advice (nor a substitute for legal advice).  No responsibility or liability is accepted by Legal Vision to anyone who relies on the information contained in this article.